2017 ORS 279C.315¹
Waiver of damages for unreasonable delay by contracting agency against public policy

(1) Any clause in a public improvement contract that purports to waive, release or extinguish the rights of a contractor to damages or an equitable adjustment arising out of unreasonable delay in performing the contract, if the delay is caused by acts or omissions of the contracting agency or persons acting therefor, is against public policy and is void and unenforceable.

(2) Subsection (1) of this section is not intended to render void any contract provision that:

(a) Requires notice of any delay;

(b) Provides for arbitration or other procedures for settlement of contract disputes; or

(c) Provides for reasonable liquidated damages. [2003 c.794 §100]

1 Legislative Counsel Committee, CHAPTER 279C—Public Improvements and Related Contracts, https://­www.­oregonlegislature.­gov/­bills_laws/­ors/­ors279C.­html (2017) (last ac­cessed Mar. 30, 2018).
 
2 OregonLaws.org contains the con­tents of Volume 21 of the ORS, inserted along­side the per­tin­ent statutes. See the preface to the ORS An­no­ta­tions for more information.
 
3 OregonLaws.org assembles these lists by analyzing references between Sections. Each listed item refers back to the current Section in its own text. The result reveals relationships in the code that may not have otherwise been apparent.